Causes of Payment Problems in the New Zealand Construction Industry
Thanuja Ramachandra1 and James Olabode BamideleRotimi2
1Department of Building Economics, University of Moratuwa, Sri Lanka
2School of Engineering, Auckland University of Technology, New Zealand
Abstract
Payment delays and losses persist in the construction industry and continue to be a key concern to industry practitioners. Therefore an exploration of the key causes of payment delays and losses is undertaken in this study with the ultimate objective of seeking mitigating solutions. The study adopted a survey approach using an online questionnaire, administered to practitioners from the New Zealand construction industry, comprising consultants, head contractors and subcontractors. The data obtained was analysed using inferential statistical techniques, including comparing means and factor analysis. Factor analysis enabled clustering of the inter-related causes of payment delays and losses in order to find reduced number of causes. Accordingly, the study found that payment problems mainly relate to contractual issues, financial strength of industry players, disputes, short-comings of payment processes and ‘domino effects’. Among them, the financial strength of critical industry players was considered central to payment problems. The study concludes that any solution to these problems must address these primary causes, as a rational starting point. Thus procuring a feasible form of financial security at the outset of a project, and the pre-qualification of the financial status of critical project participants, were found to be significant in the mitigation of construction payment risks.
Keywords: Payment problems, causal factors, factor analysis, construction, New Zealand
Paper Type: Research article
Copyright: Construction Economics and Building 2015. © 2015 Thanuja Ramachandra and James Olabode Bamidele Rotimi. This is an Open Access article distributed under the terms of the Creative Commons Attribution 4.0 Unported (CC BY 4.0) License (https://creativecommons.org/licenses/by/4.0/), allowing third parties to copy and redistribute the material in any medium or format and to remix, transform, and build upon the material for any purpose, even commercially, provided the original work is properly cited and states its license.
Citation: Ramachandra, T. and Rotimi, J.O.B., 2015. Causes of Payment Problems in the New Zealand Construction Industry, Construction Economics and Building, 15(1), 43-55. DOI: http://dx.doi.org/10.5130/ajceb.v15i1.4214
Corresponding author: Thanuja Ramachandra; Email - thanuja03@hotmail.com
Publisher: University of Technology Sydney (UTS) ePress
Introduction
Payment problems in the construction industry are not a new phenomenon. Such problems have been widely acknowledged for more than four decades by previous research (Banwell, 1964; Latham, 1994; Wu, 2010; Ye and Rahman, 2010; Wu, Kumaraswamy and Soo, 2011). The problem seems generalised, with contractors and subcontractors not getting paid their due amounts on time. This may take the form of under-payment, late or delayed payment and non-payment all together. Non-payment or under-payment refers to situations where an expected payment was never received, and/or would be considered bad debt, written off, or lost partially/fully. Late or delayed payment on the other hand, is a situation where payment is not made to head contractors or subcontractors on time, in accordance with the timelines agreed between the parties to the contract.
There is little doubt that payment defaults have many effects on project participants as well as the industry, as funding is the core of any economic transaction. Late and non-payments have an immediate effect on cash flow which in turn drives contractors and eventually subcontractors to source additional funding by means of overdraft, trade credits or other means. It was reported in China that late and eventual non-payments along with lack of security caused substantial cash flow difficulties leading to risks of insolvency of construction parties (Wu, Kumaraswamy and Soo, 2008). A prudent contractor who anticipates a payment delay from client could incorporate a risk factor against late/non-payment when pricing. However this increases the cost of projects as contractors tend to inflate tender prices if a client has a reputation for late payment (Wong and Hui, 2006). Late and non-payments lead to disputes and subsequent suspension and termination of projects. Research has revealed issues of payment as one of the major causes for disputes in the construction industry (Yates, 2003; Chan and Suen, 2005). The valuation of variations and final accounts, and failure to comply with payment provisions, are the major subject matters for disputes in construction project adjudication proceedings (Sheridan, 2003). Similarly Odeh and Battaineh (2002) suggest that failure to source adequate finance and make payments for completed works on time is a cause for construction delays attributable to project owners.
Evidence suggests that late and non-payments damage the productivity of the industry at large, but with more dire consequence to construction parties down the supply chain. Kadir et al. (2005) are of the opinion that payment delays cause slippages to material delivery which in turn impacts on labour productivity in the construction industry. With a similar opinion, Durdyev and Mbachu (2011) explained that delayed payment poses significant internal constraints to onsite labour productivity on construction projects in New Zealand. The construction industry in New Zealand is noted for its low labour productivity rates, being the fourth lowest among Organisation for Economic Co-operation and Development (OECD) countries (Constructing Excellence in New Zealand, 2008).
Countries such as the UK, USA, Australia, Singapore and New Zealand have enacted payment specific legislation and sought other legislative solutions to payment default in construction projects. In New Zealand, the Construction Contracts Act (CCA) is a payment specific legislation, which was a major step taken towards mitigating payment default within its construction industry. The CCA desired to improve the cash flow situations of constructors (Degerholm, 2003). Brand and Uher (2008) suggested that the frequency of late payments reduced with the promulgation of the Building and Construction Industry Security of Payment Act (SOP) 1999 in New South Wales, Australia. Although payment specific legislation is referred to as the Security of Payment Act in many countries, Bayley (2007) claims that these do not provide security over payment, they merely reduce payment delays. The Acts fail to provide protection against payment losses usually experienced by lower tier construction parties (Ramachandra and Rotimi, 2010). For example, Fairfax News in New Zealand (2008) indicated that the collapse of a prominent commercial construction firm left the suppliers and subcontractors of the company unpaid, with NZ$2.4 million owed to them. More recently a leading property and construction company in New Zealand went into liquidation owing NZ$139.3 million to unsecured creditors which included subcontractors and suppliers (PricewaterhouseCoopers, 2014). Similarly Reilly (2008) reported that a development company in the UK had gone into liquidation, owing €3.8 million to its suppliers and contractors. These are only a few examples of absence of security to payment defaults.
It therefore seems essential that issues of payment default are dealt with in construction industries as a matter of significance. Identifying the causes of payment problems is a key step to mitigating the problem. Literature suggests that causes for payment problems could have many dimensions. Hughes, Hillebrant and Murdoch (1998) are of the opinion that traditionally the problems associated with payments were due to either the payer is not able to pay, not willing to pay or both. However, Wu, Kumaraswamy and Soo (2011) stressed that the causes are not generic and could vary across countries due to their peculiar characteristics, economic and political set ups. This current study therefore analyses these causative factors with reference to the New Zealand construction environment, to devise ways of mitigating the problem.
Literature Review – Factors Causing Payment Problems
There are many factors associated with payment defaults in the construction industry. Hughes, Hillebrant and Murdoch (1998) explained that payment default is primarily due to two reasons: the ‘cannot’ and ‘would not’ pay attitude of payers. The ‘cannot pay’ situation refers to payers’ financial difficulties due to failure to seek funding or not having sufficient equity capital and improper cash flow management. The ‘would not’ pay situation lies with payers’ attitude. It seems common for clients to delay payment to construction contractors and subcontractors in order to manage their cash flow for other projects and reduce their overdraft facilities. In fact, Kenley (2002) notes that payment problems are deliberate; contractors hold up money and use it to pay other projects, or for their own benefits. Conversely Cotter (2005) suggests that late payments could be unintentional, although would also result in dire effects to players in the industry.
The construction industry is known for many unique characteristics which could primarily contribute to payment problems. The industry has no barriers to entry and is renowned for low capital backing, but relies heavily on cash flows to sustain its operations. This means companies or individuals with little capital base and very limited experience are able to set up construction businesses (Gibson, 2000; Pettigrew, 2005). Furthermore, in many construction projects subcontractors perform a substantial part (70-75% in some cases) of the total work (Gibson, 2000). The Australian Procurement and Construction Council (1996) reports that subcontractors perform 80-90% of the trade works associated with projects in Australia. This means that substantial upfront cash expenses would need to be sourced by these bottom tier parties to a contract. Consequently subcontractors are the worst hit by undercapitalized head contractors that cause severe financial difficulties to parties down the supply chain. The ability to sublet works arbitrarily is significant in payment problems associated with the construction industry (Sozen and Kucuk, 1999; Wu, Kumaraswamy and Soo, 2008). The Australian Procurement and Construction Council (1996) suggest that multi-tiered hierarchical structure, together with cascade payment obligations, causes late payments in the industry. This is exacerbated by the low restrictions to participants that lack skills and expertise entering the industry in Australia. This leads to improper financial management, which would then result in cash flow difficulties and eventual defaults in payment to trade creditors.
Abdul-Rahman et al. (2008) studied issues affecting payments in the construction industry and found that the perspectives of consultants and contractors differ on the causes of late payments. According to contractors, delay in certification, clients’ poor financial management, local culture/attitude, clients’ failure to implement good governance in business and underpayment of certified amounts by the clients are the most frequent causes of payment delays. Consultants identified local culture/attitude, delays in approval of claims by the client, and underpayment by the client as the top causes of payment delays. In summary the problems are traceable to clients’ poor financial management. Additionally, the industry has a culture of ‘work first, gets paid later’, which adds another dimension to the problem (Pettigrew, 2005). Other causes of payment issues, according to contractors and consultants in Malaysia include: the use of pay-when-paid clauses, disagreements on the valuation of work done, deliberate withholding of payments by clients, budget deficits for the year, poor communication and conflict between parties, delays in submitting contractors’ payment claims, and general lack of understanding of contract provisions (Danuri, et al., 2006).
Delving further into the issue, Ye and Rahman (2010) identified 40 factors which were then classified into 10 major groups. From Ye and Rahman’s list, cash flow problems due to clients’ poor financial management, ineffective utilization of funds, lack of capital to finance projects, failure to source money from banks in times of reduced sales, delay in releasing retention monies to contractors, and delay in evaluation and certification of interim and final payments, were found to be the top five factors responsible for late payments.
The foregoing review shows that the causes of payment problems are diverse and vary across countries. Some are largely attitudinal while others relate to inadequate processes that could ensure smooth cash flow within construction contracts. To add to the discourse on payment problems in the construction industry, the current study investigates the causes of payment default from a New Zealand perspective. Few empirical researches have covered the New Zealand situation and the current study approaches the investigation with the intent of seeking mitigations to anecdotal expressions of the prevalence of payment problems in New Zealand.
Research Approach
To address the objectives of the research, a survey questionnaire approach was used to collect opinions from research participants. The questionnaire enabled a determination of the factors causing payment problems in the wider New Zealand construction industry. The survey method is used in the study because it is highly efficient where a large sample selection from a pre-determined population is involved, and is relatively inexpensive (Kelley et al., 2003). Data collected through survey is treated statistically to draw inferences about the wider population. The literature reviewed indicates that payment problems within the construction industry are widespread and have ramifications for the whole of industry. A list of factors causing payment problems identified through literature review (Ye and Rahman, 2010; Pettigrew, 2005; Hughes, Hillebrant and Murdoch, 1998) was modified and considered by this study. A 5-point Likert scale ranging from ‘Not at all Important = 1’to ‘Extremely Important = 5’ was employed to determine the degree of importance of the causes of payment problems. Although scales with three, seven and nine-point levels are used, a five-point scale is normally preferred (Moser and Kalton, 1985; Saunders, Lewis and Thronhill, 2007). This enables participants to spread their views across reasonably limited (5-point) response categories rather than having to select from a much more limited (3-point) or unreasonably large number (9-point) of response categories. Data obtained from the survey was analysed using Statistical Package for the Social Sciences (SPSS) 19.0. Inferences from the study are based on descriptive and inferential (independent samples t-tests, and factor analysis) statistical techniques.
An online questionnaire survey was administered to three major industry groups: consultants, head contractors and sub-contractors based in New Zealand. Participants were approached through their respective trade and professional associations (e.g. the New Zealand Institute of Architects, New Zealand Contractors Federation, New Zealand Institute of Quantity Surveyors and Project Managers Institute of New Zealand).The number of responses obtained from the three major industry groups is 60, 15 and 40 respectively. Since the responses from head contractors (N=15) were low, relative to other categories of participants (subcontractors = 40 and consultants = 60), the responses of head contractors and sub-contractors were merged and then compared with those of consultants. A scrutiny of the responses shows that there are similarities between the profiles (profession, number of years of experience, and number of projects undertaken) of these two groups (head contractors and sub-contractors) of participants.
As a first step, an independent samples t-test was performed to determine whether the two groups of participants i.e. consultants, and constructors (head contractors and subcontractors) have different views regarding payment problems. To determine the differences in views the following hypothesis was tested.
H0: µ1 = µ2; there is no statistically significant difference between the two groups on the dependent variable, where µ1 and µ2 are the means of the two groups.
H1: µ1 ≠ µ2; there is a statistically significant difference between the two groups on the dependent variable
Following this, a factor analysis was performed to identify the overriding factors which industry players could focus on for improving payment situations in the New Zealand construction industry. The next section presents the findings in more detail and discusses the ramification of the results.
Findings and Discussion
Profile of Participants
Participants for the survey were required to indicate their profession, number of years of experience, and the number of projects they had undertaken since the implementation of the CCA in New Zealand. Table 1 provides a summary of the demographic profile of the participants. It shows that nearly equal percentages (25%) of the participants are architects and quantity surveyors while 15% and 13% are project managers and engineers respectively. Another 21% is categorized as ‘others’ which include service engineers (electrical, fire, security, air-conditioning, geo-technical, etc.), project directors, project coordinators, contracts manager etc. As per number of projects undertaken, 75% of the participants have undertaken more than 50 projects since the implementation of the CCA in 2003. The majority (over 70%) of the participants have practice experience of more than 20 years in the industry. This profile gives an indication of the reliability of the study findings.
Independent Samples t-test Results
Independent samples t-tests were performed on information obtained from the survey to compare the responses of consultants and constructors (head contractors and subcontractors) regarding the causes of payment problems. The result of the t-test is given in Table A (in Appendix). It was observed that, all the listed causes, except economic and market conditions (p-value= 0.045), are not significant at 0.05 level of significance. This means that there is no statistically significant difference between the perceptions of subcontractors and head contractors regarding the causes of payment problems. The responses were therefore merged and compared with the responses of the consultant group.
Similarly Table A (in Appendix) presents the results of the t-test performed on the responses of Consultants and Constructors (head contractors and subcontractors combined). The result shows that all causal factors are not statistically significant at 0.05 level of significance. Therefore there is no statistically significant difference between consultants and contractors perspectives on the causes of payment problems in New Zealand. All research participants were in agreement with respect to the causes of payment problems on construction projects.
Importance of Causes of Payment Problems
Table 2 presents the causes of payment problems arranged in descending order of their mean values obtained based on the responses of all three industry groups. From Table 2, 17 causes with a mean value of 3.5 and above are considered the most important causes of payment problems in construction projects. The top ten important causes are cash flow difficulties due to delays and non-payments on other projects (mean = 4.01; s.d. = 1.07), disputes over claims and responses (mean = 3.88; s.d. = 1.00), cash flow difficulties due to lack of initial capital (mean = 3.85; s.d. = 1.16), easy exit of players (mean = 3.84; s.d. = 1.12), payment culture of the industry (mean = 3.83; s.d. = 1.02), attitude of the payer (mean = 3.81; s.d. = 1.32), improper supervision and financial control (mean = 3.81; s.d. = 1.17), easy entry of players (mean = 3.80; s.d. = 1.18), cost overruns and contract failure (mean = 3.79; s.d. = 1.15), and lack of knowledge and experience in the field (mean = 3.75; s.d. = 1.10). Therefore, it would seem that cash flow difficulties due to delays and non-payments on other projects and lack of initial capital are the most important items causing payment delays and losses in New Zealand.
From the results, it is apparent that the upper tier parties on any project need to ensure the smooth flow of money in order to meet their financial commitments to creditors. Project owners generally suffer from cash flow difficulties due to insufficient initial capital, failure to source adequate funding, and improper financial management. This is in line with previous studies (Ye and Rahman, 2010; Wu, Kumaraswamy and Soo, 2008) showing that payment problems primarily affect the cash flow of contractors and cascade down the supply chain. Touran, Atgun and Bhurisith (2004) also confirmed that cash flow problems affect industry survival and are one of the leading causes of contractors’ failure. At the lower end of the supply chain, there is a cascade effect on subcontractors’ payments. Furthermore, it is not uncommon for main contractors to delay payments so that their cash flow position could be improved during work progress (Motawa and Kaka, 2009; Ye and Rahman, 2010).
Disputes over payment claims and response to claims occur due to both the default of the payers and payees. Project owners and consultants are often criticised for making arbitrary deductions from contractors’ payment claims, unreasonably withholding payments and delaying the issuance of responses to their payment claims in a bid to buy some time. Conversely contractors are blamed for claiming for uncompleted site works, over-claims, and delay in the submission of their claims. These generally create conflicts between parties and results in payments being withheld until disputes are resolved.
It would seem that the inherent characteristics of the construction industry encourage payment problems in the industry. The industry has relatively few barriers to entry and exit. This allows individuals and companies with little or no capital to start off businesses and as a consequence suffer from financial difficulties when the settlement of their payment claims becomes irregular. The industry has a unique payment culture which, in spite of the removal of conditional payment provisions of pay-if-paid and pay-when-paid clauses from payment legislation, payment problems persist. In reality subcontractors are paid upon contractors being paid by project owners and payment follows that chain order: the owner pays the head contractor, who in turn pays subcontractors and so on down the supply chain in the industry. This is confirmed by Latham (1994), Pettigrew (2005), and Wu, Kumaraswamy And Soo (2008) who suggest that payment default results from the unique characteristics of the industry. It is not surprising that the construction industry has the highest business failure rates compared to other industries (Davies, 2009; Ashworth and Hogg, 2007).
Causes of Payment Problems - Factor Analysis
A factor analysis was conducted in order to reduce the large number of causes realised into smaller groups of underlying factors. Factor analysis enabled the clustering of causes that are highly inter-correlated into a limited number of independent factors.
As a first step, the suitability of use of factor analysis for the data set was verified using Bartlett’s test of sphericity and the Kaiser-Meyer-Olkin (KMO) statistic. Bartlett’s test of sphericity tests the null hypothesis that variables are uncorrelated in the population. The Kaiser-Meyer-Olkin (KMO) statistic is used to measure sampling adequacy. Thus small values of the KMO statistic indicate that the correlations between pairs of variable cannot be explained by other variables and that factor analysis may not be appropriate. Generally a KMO of more than 0.50 is considered large enough to proceed with factor analysis (Gaur andGaur, 2006). Table 3 provides the results of these two tests. As presented in Table 3, the significant Barlett’s test statistic value of 1392.721 at p< 0.05 level confirms that the null hypothesis can be rejected, hence the use of factor analysis for the situation is appropriate. Further, the KMO statistic of 0.773 (> 0.50) obtained, confirms sampling adequacy of the data set for clustering.
| Statistical Tests | Results | |
|---|---|---|
| Kaiser-Meyer-Olkin Measure of Sampling Adequacy | .773 | |
| Bartlett’s Test of Sphericity | Approx. Chi-Square | 1392.721 |
| df | 378 | |
| Sig. | .000 | |
The next step in the factor analysis involves the extraction of underlying factors, which was done using principal axis factoring (PAF). Using the PAF method, 20 out of the 28 most important causes were able to be clustered into 6 factors. These 6 factors explain 67.6% of the total variance. Variables with factor loadings above 0.50 were considered when naming each factor. Since the six factors are likely to correlate with one another, an oblique rotation method was chosen as the best method to transform the factor matrix. In order to ensure the reliability and internal consistency between items (in the factor analysis) which make up the factors, Cronbach’s alpha reliability coefficient was calculated (Mitchell, 1996 cited in Saunders, Lewis and Thronhill, 2007). The results of the factor analysis, factor loadings and Cronbach’s alpha coefficients, are presented in Table 4.
Generally a Cronbach’s alpha value above 0.70 is an accepted test for scale reliability (Gaur and Gaur, 2006). It is noted from Table 4 that four factors have an alpha value over 0.70 while the third factor (disputes and issues) has an Alpha value of 0.627. This shows that items comprising each factor have a strong internal consistency. Since the sixth factor (others) comprises a single item, an Alpha value cannot be calculated. The sixth factor is therefore excluded from the remaining discussion.
From the factor analysis, the first factor relates to contractual issues which comprise procurement methods, contract types, standard forms of contracts (payment provisions), and legislative processes (Construction Contracts Act) that are used in any project. These causal factors are clustered under Contractual Issues. The items that make up the second factor represent the financial side of industry players; thus this factor is named Financial Strength of Industry Players. The items comprising the third factor include disputes over payment claims and responses and quality of work, as well as involvement of many parties in the structure of the industry. It could be argued that the involvement of many parties trigger associated problems such as communication and coordination, time and payment delays which result in conflicts between parties. The factor is therefore labelled, Disputes and Issues. The fourth factor has three causes of delays which represent Project Characteristics. The final factor is named the ‘Domino Effect’ as it describes the chain payment culture and cash flow difficulties due to payment delays and non-payments on other projects.
Conclusions
Unlike previous studies that focused on the generic factors causing payment delays on construction projects, this study focused on the underlying factors causing payment problems, with the aim of devising ways of mitigating payment problems. The different study participants; consultants, head contractors and sub-contractors, in the industry held unanimous views regarding the causes of payment problems in New Zealand.
The study found that the top five out of 28 causes of payment problems in the New Zealand construction industry are; cash flow problems due to delays and non-payments experienced on other projects, disputes over payment claims and responses, cash flow difficulties due to lack of initial capital, attitude of payers, easy exit of players, and the general payment culture of the industry. Subsequent clustering of the identified factors using a factor analysis provided knowledge on key areas which industry practitioners need to focus on in mitigating payment problems within the industry. From the factor analysis, the underlying factors for payment problems are six-fold: contractual issues, financial strength of industry players, disputes between players, project characteristics, the ‘domino effect’ and others. Most of the causes of payment problems fall under the clusters: financial strengths of industry players, project characteristics, and the ‘domino effect’. It is safe to conclude that the domino effect is partly due to financial weaknesses of key construction industry players.
Thus the study concludes that the financial stability of players is central to payment problems in the construction industry. Stability of payment is ensured through a regular flow of cash during work progress and ensures that all parties’ financial claims are able to be settled as and when they are due. Stable and regular payment seems to be the chief mitigating solution to payment problems in the construction industry. Adjustments to contractual provisions that could guarantee financial stability may include the procurement of some sort of financial security at the outset of a project. Thus any payment default is immediately indemnified by the security provider. It may also be worth incorporating mandatory requirements for prequalification of the financial status of critical funding parties to any contract. This way, vulnerable parties can be assured of the financial status of critical funding parties. The applicability of these few suggestions are recommended for further investigation as the current study is limited to identifying the key causes of payment problems. Further, the study recommends that the viewpoints of project owners are significant and should be collected in future study investigations as the current study had simply used consultants as proxies to project owners.
References
Abdul-Rahman, A., Munaaim, M.E.C., Danuri, M.S.M. and Berawi, M.A.,2008. Issues affecting payments in the building and construction industry of a rapidly developing economy. Building Engineer, November, 4-10.
Ashworth, A. and Hogg, K.,2007. Willis’s practice and procedure for the quantity surveyor. UK: Blackwell Publishing Ltd.
Australian Procurement and Construction Council,1996. National Action on Security of Payment in the Construction Industry. Deakin West, A.C.T: APCC.
Banwell, H.,1964. The placing and management of contracts for building and civil engineering work.London: HMSO.
Bayley, G.,2007.Construction adjudication in New Zealand under the Construction Contracts Act 2002. In:9th LEADR International ADR conference. Wellington New Zealand.19-21 September.
Brand, M.C. and Uher, T.E.,2008. Review of the performance of security of payment legislation in New South Wales. In:The RICS Construction and Building Research Conference COBRA 2008. Dublin Institute of Technology, Ireland.4-5 September.
Chan, E.H.W. and Suen, H.C.H., 2005. Dispute resolution management for construction projects in China. Management Decision, 43(4), p.589. doi: http://dx.doi.org/10.1108/00251740510593576
Constructing excellence in New Zealand, 2008. New Zealand Construction Industry Vision 2025, Constructing Excellence (NZ) Ltd. 3.
Cottor, P.,2005. Late payment: Why it pays to know your customers, Experian’s Business Information Division.
Danuri, M.S.M., Munaaim, M.E.C., Rahman, H.A. and Hanid, M.,2006. Late and non-payment issues in the Malaysian Construction Industry - Contractor’s perspective. In:International Conference on Construction, Culture, Innovation and Management (CCIM). Dubai (United Arab Emirates).26-29 November.
Davies, J.,2009. Protect yourself from insolvency in the construction industry. Available at:http://www.bsdlive.co.uk/ [Accessed 24 January 2010].
Degerholm, P.,2003. Managing Contractors’ Cashflow. Auckland: Rawlinsons Media Limited.
Durdyev, S. and Mbachu, J.,2011. On-site labour productivity of New Zealand construction industry: Key constraints and improvement measures. Australasian Journal of Construction Economics and Building.11(3) pp.18-33. doi: http://dx.doi.org/10.5130/ajceb.v11i3.2120
Fairfax NZ News, 2008. Not a cent for builder’s creditors: Big claims and few cases. The Dominion Post, [online] 29 June. Available at: http://www.stuff.co.nz/national/510911/Not-a-cent-for-builders-creditors.
Gaur, A.S. and Gaur, S.S.,2006. Statistical Methods for Practice and Research: A guide to data analyis using SPSS. New Delhi: Sage Publications India Ltd.
Gibson, A.,2000. Economic Darwinism calls for intervention. The New Zealand Herald. [online] 24 May. Available at: http://www.nzherald.co.nz/business/news/article.cfm?c_id=3&objectid=138048.
Hughes, W., Hillebrant, P. and Murdoch, J.,1998. Financial protection in the UK building Industry. London: E & FN Spon. doi: http://dx.doi.org/10.4324/9780203478226
Kadir, M.R.A., Lee, W.P., Jaafar, M.S., Sapuan, S.M. and Ali, A.A.A.,2005. Factors affecting construction labour productivity for Malaysian residential projects. Structural Survey, 23(1), pp.42-54. doi:10.1108/02630800510586907. doi: http://dx.doi.org/10.1108/02630800510586907
Kelley, K., Clark, B., Brown, V. and Sitzia, J.,2003. Good practice in the condust and reporting of survey research. International Journal for Quality in Health Care, 15(3), pp.261-66. doi: http://dx.doi.org/10.1093/intqhc/mzg031
Kenley, R., 2002. Milking the cash cow. The New Zealand Herald. [online] 17 August. Available at: http://www.nzherald.co.nz/business/news/article.
Latham, M.,1994. Constructing the team:Final report of the government industry review of procurement and contractual arrangements in the UK construction industry. London: HMSO.
Moser, S.C. and Kalton, G.,1985. Survey methods in social investigation. 2nd ed. Aldershot Hants Dartmouth Publishing Co Ltd.
Motawa, I. and Kaka, A.,2009. Modelling payment mechanisms for supply chain in construction. Engineering Construction and Architectural Management, 16(4), pp.325-36. doi:10.1108/09699980910970824. doi: http://dx.doi.org/10.1108/09699980910970824
Odeh, A.M. and Battaineh, H.T.,2002. Causes of construction delay: Traditional contracts. International Journal of Project Management, 20(1),pp.67-73. doi: http://dx.doi.org/10.1016/S0263-7863(00)00037-5
Pettigrew, R.,2005. The legal and contractual background. In: Payment under construction contracts legislation. Heron Quay Thomas Telford.
PricewaterhouseCoopers, 2014. Receivers’ second six monthly report on the state of affairs. Available at: http://www.pwc.co.nz/PWC.NZ. [Accessed 6April2014].
Ramachandra, T. and Rotimi, J.O.,2010. Review of methods for mitigating payment risks in construction. International Research Conference on Sustainability in Built Environment. Colombo, Sri Lanka, pp. 198-207.
Reilly, J.,2008. Top luxury developer forced into liquidation. The Independent. [online] 01 June. Available at:http://www.independent.ie/national-news/top-luxury--developer-forced-into-liquidation-1393785.html.[Accessed 3 June 2010].
Saunders, M., Lewis, P. and Thronhill, A.,2007. Research methods for business students. 6th ed. Harlow, England: Pearson Education.
Sheridan, P.,2003. Claims and disputes in construction. ConstructionLaw Journal, 12(1), pp.3-13.
Sozen, Z. and Kucuk, M.A.,1999. Secondary subcontracting in the Turkish construction industry. Construction Management and Economics, 17(2),pp.215-20. doi: http://dx.doi.org/10.1080/014461999371718
Touran, A., Atgun, M. and Bhurisith, L.,2004. Analysis of the United States Department of Transportation prompt pay provisions. Journal of Construction Engineering and Management, 130(5), pp.719-25. doi: http://dx.doi.org/10.1061/(ASCE)0733-9364(2004)130:5(719)
Wong, J.T.Y. and Hui, M.C.E., 2006. Construction project risks: further considerations for constructors’ pricing in Hong Kong. Construction Management and Economics, 24(4),pp.425-38. doi: http://dx.doi.org/10.1080/01446190600601602
Wu, J.,2010. Securing payment in the Main Land China construction industry: the problem of payment arrears and the remedial measures. PhD. The University of Hong Kong.
Wu, J., Kumaraswamy, M.M. and Soo, G., 2008. Payment Problems and Regulatory Responses in the Construction Industry: Mainland China Perspective. Journal of Professional Issues in Engineering Education and Practice 134(4),pp.399-407. doi: http://dx.doi.org/10.1061/(ASCE)1052-3928(2008)134:4(399)
Wu, J., Kumaraswamy, M.M. and Soo, G., 2011. Regulative Measures Addressing Payment Problems in the Construction Industry: A calculative understanding of their potential outcomes based on gametric models. Journalof ConstructionEngineering and Management137(8),pp.566-73.
Yates, D.,2003. Can claims and disputes (in construction contracts) be prevented or reduced? Building Journal, Hong Kong, China (June).
Ye, K.M. and Rahman, A.H.,2010. Risk of late payment in the Malaysian construction industry. International Scholarly and Scientific Research and Innovation, 4(5), pp.81-9.