Contract delay: what is it and how are we performing?
This paper examines the management of contract delays in the construction industry as currently practised, and suggests some best practice alternative methods.
Research results about the level of contractor’s time management skills were analysed to determine the related impact on their ability to manage contract delays. A comparison was made between three conditions of contracts used in New Zealand to determine how delay management should be managed with a discussion about how the different contract conditions distribute risk among the parties. Recommendations were made to improve contract conditions, up-skill industry practitioners and ensure student graduates have adequate delay management skills.
Constructing Excellence in New Zealand. (Retrieved April 1, 2011). www.constructing.co.nz.
Barry, D. (2009). Beware the Dark Arts! Delay Analysis and the Problems with Reliance on Technology. Society of Construction Law, 1-14.
Dr Critchlow, Julian; Farr, Alastair; Briggs, Steve; Hammond, John; Pickavance, Keith; Professor Lavers, Anthony. (2005). The Great Delay Analysis Debate. Society of Construction Law.
Farrow, T. (2001). Delay Analysis - Methodoly and Mythology. Society of Construction Law.
Lal, H. (2002). Extension of Time: The Conflict Between The Prevention Principle and Notice Requirements as a Condition Precedent. Society of Construction Law."
Lal, H. (2007). The Rise and Rise of Time-bar Clauses for Contractors' Claims: Issues for Construction Arbitrators. Society of Construction Law.
Lim, T. (2009). Essence of Time in Construction Contracts. The Australasian Journal of Construction Economics and Building, 1-6.
Marrin QC, J. (2002). Concurrent Delay. Society of Construction Law.
McDonough, F. (2006). Analysing and Handling Delays. Constructing NZ, 7.
McDonough, F. (October 2006). Analysing and Handling Delays in. Constructing NZ, 6-7.
Nash, S. C. (2002). Delay and Disruption: Legal Considerations. Society of Construction Law.
New Zeland Centre for Advanced Engineering (CAENZ). (Retrieved April 1, 2011). www.caenz.com.
Pickavance, K. (2001). Principles and Policies in Delay Analysis. Society of Construction Law.
Pickavance, K. (2009). Managing the Risk of Delayed Completion in the 21st Century: The CIOB Research. Society of Construction Law.
Pickavance, Keith; MacLaughlin, Wendy. (2005). A Little of Time at Large: Proof of a Reasonable Time to Complete in the Absence of a Completion Date. Society of Construction Law.
Pinto, J. K. (2010). Project Management Achieving Competitive Advantage 2nd Edition. New Jersey: Pearson Education.
Professor Jones, D. (2009). Can Prevention Be Cured By Time Bars? Society of Construction Law.
Stulic, M. (2010). Prevention and the Allocation of the Risk of Project Delays: Evolution or Revolution? Society of Construction Law.
The Society of Construction Law. (October, 2002). Delay and Disruption Protocol. Available from www.eotprotocol.com.
Winter, J. (2009). How Should Delay Be Analysed - Dominant Cause and its Relevance to Concurrent Delay. Society of Construction Law.
Metrics powered by PLOS ALM